Особенности международного контракта подряда между Китаем и Россией

Дипломная работа - Экономика

Другие дипломы по предмету Экономика

orce.

.6. Ownership on building object in his(its) paid by Customer of a part and on accepted by completed construction object is realized by Customer. The risk of possible his(its) destruction or damages undertakes After acceptance of the object Customer.ITEM 9. WARRANTIES ON DELIVERED OBJECT

.1. The Contractor guarantees:quality used material, design, equipment and systems,correspondence to their design schedule, state standard and standard specifications, suply their corresponding to certificate, technical passport and the other document, certifying their quality;quality of the execution of all functioning in accordance with design documentation and acting rate and standard specifications;timed removal defect and defect, revealled at acceptance of the functioning and at period guaranteed usages an object;operating the engineering systems and equipment under normal usage of the object.

.2. The Customer guarantees:timed execution of their own obligations on persisting contract;quality of the equipment, material and product of the supply of the Customer. In events of their discrepancy specified in p. 9.1 persisting contract to requirements Customer provides their change at periods, coordinated with Contractor.

.3. The Warranty period to normal usage of the object and falling into it engineering systems, equipment, material and functioning ustanavlivaetsya10 months since date of the signing by parties of the acceptance report of the ready object.

.4. At failure of the Contractor from formation or signing the act discovered defect Customer forms the unilateral act on base of the skilled expert operation that excludes the right of the parties to apply to court of arbitration on given to question.ITEM 10. PAYMENTS And PAYMENTS

.1. The Customer monthly not later 10 numbers pays the Contractor 20 percents of the cost executed for previous period of the functioning, as well as 30 percents of the cost material, завезенных by Contractor to construction site, but not used in construction on the end of this period. The Paided cost these material remains at payment of the executed functioning in following month.

.2. The Payments for material and products, transferred by Customer Contractor, are produced on the prices of their aquisition with provision for transport expenses and expenses of the Customer on stocking up and keeping these material and product. At transfer Contractor material, the product and equipment Customer will simultaneously transfer him part provided cost estimate of the facilities on заготовительно-storage expenses in amount 30 percents of these facilities on material and product and 20 percents on equipment, but in the event of transfer of the equipment in zone of the montage - 15 percents.

.3. The Balance for executed work on object are produced by Customer not later 30 days following full termination his(its) construction, including removal revealled defect, on the grounds of acceptance report of the object in usage, executed in accordance with the established order.Payment is produced on negotiated price, installed on object in item 2 persisting contract and elaborated in additional agreements, with зачетом all earlier made payments on him.ITEM 11. PROPERTY LIABILITY of the PARTIES

.1. For breach by Customer of the treaty obligationses he pays the Contractor:the delay of the transfer Contractor construction site, documentation, specified in items 4.1, 4.2, 4.5 persisting contract, equipment, material and product fine in amount 300 roubles for each day of the delinquency;transfer for montage некомплектного equipment - a fine in amount 300 for each day of the delay for this reason his(its) montage.

.2. Except sanction for nonperformance of the obligations on a contract party in fault indemnifies other party непокрытые forfeit losses including missed profit.

.3. The Payment of the fines, spume and forfeit, as well as indemnifying the losses does not free the parties from performance of their own obligations in nature.This contract is formed in five copies - on one on two languages for each parties and financing bank.Customer _____________________________ (signature)Contractor ____________________________ (signature)